`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 1 of 44
`
`EXHIBIT "A"
`EXHIBIT “A”
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 2 of 44
`
`IN THE SUPERIOR COURT OF GWINNETT COUNTY
`
`Optum Construction Group, LLC
`
`STATE OF GEORGIA
`
`E-FILED IN OFFICE - MX
`CLERK OF SUPERIOR COURT
`GWINNETT COUNTY, GEORGIA
`21-A-04512-4
`6/11/2021 3:13 PM
`TIANA P. GARNER, CLERK
`
`CIVIL ACTION
`NUMBER: (cid:9)
`
`21-A-04512-4
`
`VS.
`Ethicon, Inc.
`
`PLAINTIFF
`
`DEFENDANT
`
`SUMMONS
`
`TO THE ABOVE NAMED DEFENDANT:
`
`You are hereby summoned and required to file with the Clerk of said court and serve upon the Plaintiffs attorney, whose name
`and address is:
`G. Marshall Kent, Jr.
`Fox Rothschild LLP
`999 Peachtree Street, Suite 1500
`Atlanta, Georgia 30309
`
`an answer to the complaint which is herewith served upon you, within 30 days after service of this summons upon you, exclusive of
`the day of service. If you fail to do so, judgment by default will be taken against you for the relief demanded in the complaint.
`
`11TH
`
`This
`
`day of
`
`JUNE
`
`21
`
`20
`
`Tiana P. Garner
`
`Clerk of Si^{»^
`
`ior Cour
`
`By.
`
`ia
`
`Deputy Clerk
`
`4A
`
`INSTRUCTIONS: Attach addendum sheet for additional parties if needed, make notation on this sheet if addendum sheet is used.
`
`SC-I Rev. 2011
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 3 of 44
`
`E-FILED IN OFFICE - MX
`CLERK OF SUPERIOR COURT
`GWINNETT COUNTY, GEORGIA
`21-A-04512-4
`6/11/2021 3:13 PM
`TIANA P. GARNER, CLERK
`
`IN THE SUPERIOR COURT OF GWINNETT COUNTY
`STATE OF GEORGIA
`
`OPTUM CONSTRUCTION GROUP,
`LLC,
`
`v.
`
`ETHICON, INC.,
`
`Plaintiff,
`
`Defendant.
`
`CIVIL ACTION FILE NO.
`
`21-A-04512-4
`
`COMPLAINT
`
`COMES NOW Plaintiff Optum Construction Group, LLC ("Optum"), a licensed Georgia
`
`commercial general contractor, and states its claims against Defendant Ethicon, Inc. ("Ethicon"),
`
`a New Jersey corporation and wholly owned operating subsidiary of Johnson & Johnson, Inc., as
`
`follows:
`
`1.
`
`Plaintiff Optum is a Georgia limited liability company that maintains its principal place of
`
`business in Gainesville, Hall County, Georgia. Optum is engaged in the business of providing
`
`labor and materials for the performance of commercial construction projects as a licensed
`
`commercial general contractor. Optum's member(s) reside in Georgia.
`
`2.
`
`Defendant Ethicon is a New Jersey corporation that maintains its registered agent and
`
`office in Gwinnett County, Georgia. Ethicon may be served with a Summons and service copy of
`
`this Complaint through service upon Ethicon's registered agent, CT Corporation System, 289
`
`Culver Street, LawrenCeville, Gwinnett County, Georgia 30046-4805.
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 4 of 44
`
`Jurisdiction and venue are proper in this Court because Defendant Ethicon maintains its
`
`registered agent in Gwinnett County.
`
`4.
`
`Defendant Ethicon operates and maintains a large plant and manufacturing facility that is
`
`located at 655 Ethicon Circle, Cornelia, Habersham County, Georgia 30531. Optum hereby
`
`brings this action to recover monies owed Optum by Ethicon, totaling $951,634.00, for certain
`
`work performed and/or supervised by Optum on the Ethicon AHU 17A Project, located at 655
`
`Ethicon Circle, Cornelia, Habersham County, Georgia 30531 (the "Project"). Optum is also owed
`
`retainage for its work performed and completed some time ago for a Project called the "Sparks
`
`Project," that was also performed at the Ethicon plant, in the amount of $82,903.00.
`
`5.
`
`Optum served as the outside general contractor for Plant Projects at Ethicon for many years.
`
`Optum would be compensated for its work pursuant to Purchase Orders issued by Ethicon, the
`
`timing of which was generally determined by Ethicon Plant construction managers/supervisors.
`
`These managers/supervisors dealt with internal budgets that contemplated how and what specific
`
`I
`
`work would be directed to be performed, and how the costs thereof would be allocated internally
`
`within the Company.
`
`6.
`
`On or about July 5, 2018, and based on design drawings prepared by Stewart Engineering,
`
`an engineering consultant regularly used by Ethicon Plant personnel, a S 1 .4 million Purchase Order
`
`was issued to Optum for installation of an Air Handling Unit, that was originally contemplated by
`
`Stewart's drawings to be installed on an elevated platform "penthouse," where Ethicon then
`
`2
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 5 of 44
`
`maintained its mechanical, electrical, plumbing and HVAC controls for the Plant. A true and
`
`accurate copy of that Purchase Order is attached hereto as Exhibit "1
`
`However, in early August
`
`of 2018, after Optum and Ethicon's internal managers conducted a further assessment of the
`
`Project as initially planned/designed (that resulted in the discovery of material structural
`
`issues
`
`and deficiencies in the plan/design based on the weight of the unit and inadequacy of the
`
`foundation to accommodate the Unit), Optum was directed by Ethicon to consult one or more
`
`outside engineering firms, and arrange for a preliminary layout for a freestanding mechanical
`
`building to house the AHU 17A Project. This layout was obtained by Optum from Trinity
`
`Engineering, a reputable Gainesville firm.
`
`7.
`
`Thereafter, Mr. Raymond Harris of Ethicon (Ethicon's Onsite Facilities Engineer -
`
`Georgia) issued a directive to Mr. Ed Maxwell of Optum instructing Optum to proceed to obtain
`
`new (civil, architectural, and structural, as well as mechanical, electrical and plumbing) drawings
`
`for a freestanding mechanical building. Optum proceeded to arrange for these drawings, and in
`
`February and March of 2019, Ethicon proceeded to evaluate the requested drawings for the
`
`erection of the freestanding building, that was two and a half times the square footage/size of the
`
`original proposed penthouse.
`
`8.
`
`T"-he-re vised foundation-and-site-drawings- were considered7as-was~theTactthat-substantiaT
`
`demolition work and relocation of plumbing, piping and other utilities would be involved in the
`
`contemplated improvements. Ethicon representatives were made fully aware of all relevant design
`
`issues by June of 2019.
`
`3
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 6 of 44
`
`9.
`
`By this time, and after Bid Documents were issued by Trinity Engineering for pricing
`
`purposes, Optum was asked to submit its bid to perform the requested work by Messrs. Raymond
`
`Harris and Bryan Willett (another Onsite Facilities Engineer) ofEthicon. A true and accurate copy
`
`of the bid presented by Optum to Mr. Harris of Ethicon is attached as Exhibit "2." At that time,
`
`Mr. Harris requested that Optum's Bid be delivered to him in person (not by email). Respecting
`
`his perceived sensitivity, Optum complied, and Mr. Maxwell and another employee of Optum met
`
`with Mr. Harris to communicate that Bid.
`
`10.
`
`During that meeting, and after Mr. Harris learned that the additional cost associated with
`
`the Project would exceed S900,000.00, Mr. Harris informed Optum he had a way to cover the
`
`additional cost (stating he would bury that cost into the budget for another Project if necessary),
`
`and directed Optum to proceed.
`
`11.
`
`Shortly thereafter,
`
`the drawings were issued and submitted for permitting, and Mr.
`
`Maxwell met with Mr. Sean DuBois of Ethicon (who is the Supervisor of Messrs. Harris and
`
`Willett at the Plant) and walked the site, discussing and detailing the improvements that would be
`
`performed. On June 10, 2019, Optum "broke ground" and commenced construction.
`
`(cid:9)
`
`I-2t
`
`Throughout
`
`these discussions, Ethicon representatives communicated their intention to
`
`issue one or more amended Purchase Orders to reflect the increased cost associated with what were
`
`clearly "cardinal changes" to the Work. A summary of the additional scope of Work involved in
`
`constructing the Project in accordance with the modified plans/design is attached hereto as Exhibit
`
`4
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 7 of 44
`
`"3". Optum, that had a long history of working with Ethicon at the Plant on numerous projects,
`
`reasonably relied upon Ethicon's representations that one or more amended Purchase Orders
`
`would be issued in proceeding to perform the Work.
`
`13.
`
`Inexplicably, however, as the Work progressed, and neared completion, Ethicon personnel
`
`became increasingly hesitant and evasive about discussing the status of the amended Purchase
`
`Order(s) Optum was misled to understand would be forthcoming.
`
`It is Optum's information and
`
`belief that notwithstanding Ethicon's direction to Optum to perform the modified Project,
`
`Ethicon's construction managers/supervisors at
`
`the Plant
`
`failed to properly budget
`
`for the
`
`substantial modifications to the original Purchase Order.
`
`14.
`
`As the Project neared completion, Mr. Maxwell was approached by Mr. DuBois and
`
`presented with a choice: Optum could write-off and absorb the cost of the additional Work over
`
`and beyond what was reflected in the original Purchase Order (write the excess cost off) and finish
`
`the job (in which case Mr. DuBois said Optum would be allowed to continue to receive future
`
`Work at the Plant, and maintain its relationship with Ethicon), or Optum could pursue a claim for
`
`what it was owed for that additional Work, in which case Optum would be banned from the site,
`
`and never receive further work from Ethicon.
`
`15.
`
`Given its obligation to collect what is owed on behalf of its subcontractors and suppliers,
`
`and as a matter of principle, Optum elected the latter alternative. Optum and its subcontractors
`
`subsequently received a directive from Ethicon to demobilize from the Project.
`
`5
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 8 of 44
`
`16.
`
`Optum proceeded to demand payment for the substantial additional work Ethicon directed
`
`Optum to perform. After initially citing to the lack of the Amended Purchase Order as its purported
`
`excuse for refusing to pay Optum, Ethicon subsequently retained outside counsel, and proceeded
`
`to cite to alleged "defective work" on prior projects performed by Optum, including the preceding
`
`AHU Unit 7/10 and DEHUM Projects, as well as alleged defective work performed on the 17A
`
`project. Ethicon has now adopted the position it is entitled to offset against amounts owed Optum
`
`on the 17A project for alleged deficiencies related to the AHU7 Unit 7/10 and DEHUM Projects,
`
`even though Ethicon previously paid Optum for those prior projects. Ethicon's actions in
`
`exercising its alleged offset has effectively caused Optum not to be fully compensated for those
`
`prior projects. Ethicon has also refused to pay the balance of $82,903.00 owed to Optum for its
`
`performance of the "Sparks Project" at the Plant, that was completed some time ago. A true and
`
`accurate summary of the balance owed for that Project is attached hereto as Exhibit "4".
`
`17.
`
`In doing so, Optum also shows that Ethicon has grossly inflated the amount of its alleged
`
`offsets for deficiencies. Ethicon has sought to justify its unauthorized offsets by citing to a "report"
`
`prepared by Stewart Engineering,
`
`the same engineering consultant
`
`that
`
`issued the original
`
`(cid:9)
`
`(defective) plans- that -needed to-be-revised -and modified- in- the-first-placer Curiously, Ethicon -*
`
`sought to procure this "dubious report" from this consultant, even though Ethicon requested Optum
`
`to use Trinity Engineering, a reputable Gainesville, Georgia mechanical, electrical and plumbing
`
`(MEP) engineering firm, to prepare and submit the permitted plans for the modified project. To
`
`date, Ethicon has inexplicably failed to consult with Trinity.
`
`6
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 9 of 44
`
`18.
`
`Curiously, many of the alleged deficiencies identified by Ethicon's "consultant" (Stewart
`
`Engineering) are premised upon expectations or purported specifications not contained in the
`
`permitted plans. Even after receiving the permitted plans from Optum, Ethicon has persisted in its
`
`allegations, without requesting Trinity to provide input or otherwise inspect the work. The alleged
`
`deficiencies further appear wildly inflated in terms of both alleged scope and expense to address.
`
`Moreover, despite repeated requests by Optum and its primary commercial HVAC subcontractor
`
`on this Project, Sluss + Padgett, to inspect the Plant site and Ethicon's alleged deficiencies (to
`
`determine whether any corrective or warranty work is appropriate under
`
`the attendant
`
`circumstances), Ethicon continues to refuse to provide Optum or its subcontractors with access to
`
`the Plant to inspect their work.
`
`Ethicon's ongoing failure and refusal
`
`to do so is effectively
`
`preventing Optum and its subcontractors from assessing or addressing Ethicon's alleged "issues"
`
`and constitutes an intentional failure by Ethicon to mitigate its alleged "damages".
`
`19.
`
`While Optum cannot understand what has motivated Ethicon representatives to adopt what
`
`Optum contends are dishonest and unreasonable positions, and irrespective of what internal budget
`
`at Ethicon should bear the costs of this additional work, Optum is legally entitled to payment of
`
`all outstanding amounts owed for its Work, and reiterates its prior demand for payment.
`
`20.
`
`Based upon the foregoing facts,
`
`it
`
`is apparent
`
`that Ethicon personnel engaged in a
`
`conspiracy and pattern of ongoing fraudulent conduct to misrepresent Ethicon's present intent to
`
`deliver an amended purchase order that would incorporate the significant additional work. Ethicon
`
`personnel also misrepresented Ethicon's present intent to compensate Optum for the significant
`
`7
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 10 of 44
`
`additional cost
`
`incurred by Optum to perforin the additional work at Ethicon's direction,
`
`in
`
`detrimental reliance upon Ethicon's representations.
`
`21.
`
`This additional scope of work constitutes a cardinal change to the original Purchase Order,
`
`and as such Ethicon is obligated to compensate Optum for this additional work, since any failure
`
`to do so would cause Ethicon to be unjustly enriched under Georgia law.
`
`22.
`
`Ethicon is similarly obligated to compensate Optum for its performance of the "Sparks
`
`Project," to prevent Ethicon from being unjustly enriched. Ethicon's construction managers and
`
`supervisors at the Ethicon Plant are fully aware of the work performed by Optum on these Projects,
`
`and irrespective of how they "budgeted" for these Projects, Optum should be paid.
`
`23.
`
`Optum has further filed its Claim of Lien against the Project
`
`for the total amount of
`
`$951,634.00 owed by Ethicon to Optum and its subcontractors on the AHU 17A Project. A true
`
`and accurate copy of Optum's Claim of Lien, filed on September 8, 2020 at Lien Book 00053,
`
`Pages 00366-0070 of the Habersham County records, together with Optum's Demand for Payment
`
`and Notice of its Lien Claim, is attached hereto as Exhibit "5."
`
`COUNT ONE -BREACH OF CONTRACT/ACCOUNT
`
`24.
`
`Optum incorporates paragraphs 1-23 hereof by reference as if all such paragraphs were
`
`restated herein verbatim.
`
`8
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 11 of 44
`
`25.
`
`During the period from June of 2019 through August of 2020, Optum provided labor and
`
`materials, as well as construction management services required to perform improvements
`
`contemplated under the AHU 17A Project,
`
`including cardinal changes to the original Purchase
`
`Order issued to Optum that were directed by Ethicon and the Project Owner.
`
`The work and improvements that are the subject of Optum's outstanding invoice was
`
`26.
`
`delivered to and received by Ethicon, the Project Owner.
`
`27.
`
`Ethicon breached its obligations under the original Purchase Order and cardinal change
`
`directive issued pursuant thereto. Despite repeated requests and demands by Optum, Ethicon has
`
`also failed and refused to pay Optum its $951,634.00 invoice and overhead/profit related to
`
`cardinal change directives, as well as the remaining amount of $82,903.00 owed for the "Sparks
`
`Project." Ethicon is liable to Optum for these amounts pursuant to the Purchase Order, as Ethicon
`
`directed it to be modified, or alternatively on account.
`
`28.
`
`A true copy of Optum's demand letter is attached in Exhibit "5." Optum shows that it is
`
`entitled to recover additional amounts owed to Optum, attributable to additional administrative
`
`.
`
`(cid:9)
`
`costs-caused by-the change-directives -imposed- by-Ethicon,- -as-wel-l-as interest- accrued-on the
`
`outstanding balance owed Optum by Ethicon.
`
`9
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 12 of 44
`
`29.
`
`Pursuant
`
`to O.C.G.A. § 7-4-16 and the contractual
`
`terms between Optum and Ethicon,
`
`Ethicon owes interest to Optum accrued on the outstanding amount at the rate of 18% per annum
`
`from the date its invoice and final payment became due.
`
`30.
`
`All conditions precedent
`
`to Optum's right to payment have been satisfied, waived or
`
`otherwise excused.
`
`COUNT TWO - ALTERNATIVE CLAIM FOR QUANTUM MERUIT/VALEBANT
`
`AND/OR UNJUST ENRICHMENT
`
`31.
`
`Optum incorporates paragraphs 1-30 hereof by reference as if all such paragraph were
`
`restated herein verbatim.
`
`32.
`
`Optum provided labor and materials, as well as construction services at the request of
`
`Ethicon, reflected in the invoice submitted by Optum.
`
`33.
`
`The labor, materials and services requested by Ethicon are valuable to Ethicon.
`
`34.-
`
`Ethicon accepted the labor, materials and services provided by Optum, and has been
`
`unjustly enriched to the extent it has failed to compensate Optum.
`
`10
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 13 of 44
`
`35.
`
`Ethicon is obligated in quantum meruit and/or quantum valebant
`
`to pay Optum the
`
`reasonable value of the labor, materials and services provided by Optum at the Project, at Ethicon's
`
`direction and request. Alternatively, Ethicon is obligated to pay Optum the reasonable value of
`
`the labor, materials and services Optum delivered at the Project to prevent Ethicon from becoming
`
`unjustly enriched.
`
`36.
`
`The reasonable value of the labor, materials and services delivered at
`
`the Project and
`
`thereby provided to Ethicon is not less than $951,634.00, as well as the amount of $82,903.00 that
`
`remains owed for the "Sparks Project".
`
`COUNT THREE - BREACH OF IMPLIED PROMISE NOT TO INTERFERE WITH
`
`PERFORMANCE OF CONTRACT
`
`37.
`
`Optum incorporates paragraphs 1-36 hereof by reference as if all such paragraph were
`
`restated herein verbatim.
`
`38.
`
`Ethicon had an implied duty not
`
`to hinder, delay or interfere with the conduct and
`
`performance of the Work, as modified, directed to be performed by Ethicon.
`
`39.
`
`Nonetheless, through Ethicon's delivery of an unfair ultimatum to Optum, its intentional
`
`failure and refusal
`
`to allow Optum to complete its Work at
`
`the Project, Ethicon's arbitrary
`
`imposition of change orders and directives without providing the amended purchase order Ethicon
`
`represented would be forthcoming on numerous occasions, as well as Ethicon's subsequent failure
`
`11
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 14 of 44
`
`to cooperate with and timely compensate Optum, Ethicon effectively delayed and impeded Optum
`
`in its performance of the Project. Ethicon's purposeful failure and refusal to permit access to the
`
`Plant to Optum and its subcontractors to inspect the alleged deficiencies claimed by Ethicon, so
`
`Optum could proceed in good faith to access the need for any corrective or warranty work, is
`
`another example of Ethicon's breach of this material
`
`implied contractual obligation.
`
`40.
`
`Optum has incurred compensatory damages directly and proximately flowing from the
`
`breach by Ethicon and its agents of their implied duty not to interfere with Optum 's performance
`
`in an amount that shall be established by the evidence at trial.
`
`COUNT FOUR - VIOLATION OF GEORGIA PROMPT PAY ACT
`
`Optum incorporates paragraphs 1-40 hereof by reference as if all such paragraph were
`
`41.
`
`restated herein verbatim.
`
`42.
`
`The failure of Ethicon to compensate Optum in a timely manner in accordance with the
`
`Purchase Order (as modified) constitutes a violation of the Georgia Prompt Pay Act, O.C.G.A. §
`
`13-1 1-1 et seq. Both Optum's prior demand letter, as well as service of this Complaint upon
`
`Ethicon constitutes notice of Optum's demand for payment under this Act, in accordance with
`
`O.C.G.A. § 13- I
`
`I -/(a).
`
`43.
`
`Pursuant to the Georgia Prompt Pay Act, Optum is entitled to recover the outstanding
`
`balance of S95 1,634.00 owed by Ethicon for the labor, materials and services provided by Optum
`
`on the AHU 17A Project overhead and profit related thereto, as well as the additional amount of
`
`12
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 15 of 44
`
`$82,903.00 owed for the "Sparks Project", together with interest accrued thereon at the commercial
`
`rate of 1 2% per annum.
`
`44.
`
`Optum is also entitled to recover its reasonable costs incurred to collect this outstanding
`
`balance, including reasonable attorneys' fees and costs, from Ethicon, pursuant to O.C.G.A. § 13-
`
`1 1-8.
`
`COUNT Fi VE - ATTORNEYS' FEES AND EXPENSES OF LITIGATION
`
`45.
`
`Optum incorporates paragraphs 1-44 hereof by reference as if all such paragraph were
`
`restated herein verbatim.
`
`46.
`
`By failing to pay Optum despite repeated demands by Optum that it be paid, Ethicon has
`
`acted in bad faith, been stubbornly litigious and has caused Optum unnecessary trouble and
`
`expense.
`
`47.
`
`Optum is entitled to recover its reasonable expenses of litigation, including reasonable
`
`attorney's fees, from Ethicon, pursuant to O.C.G.A. § 13-6-1 1.
`
`COUNT SIX - FRAUD/CONSPIRACY
`
`48.
`
`Optum incorporates paragraphs 1-47 hereof by reference as if all such paragraph were
`
`restated herein verbatim.
`
`13
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 16 of 44
`
`49.
`
`Optum shows that Ethicon representatives materially misrepresented Ethicon's intent to
`
`issue a modified Purchase Order for the AHU 17A Project to Optum, and thereby fraudulently
`
`induced Optum to execute and perform the material modifications to the original Purchase Order
`
`directed by Ethicon. These parties also knew or should have known that for reasons internal
`
`to
`
`Ethicon, a modified Purchase Order was either not authorized, or was not forthcoming. Optum
`
`justifiably relied upon Ethicon's misrepresentations to its detriment.
`
`Optum subsequently
`
`provided labor, materials and supplies to the Project at the request and direction of Ethicon, for
`
`which Ethicon purposefully and intentionally failed to compensate Optum.
`
`50.
`
`In procuring the Work delivered by Optum, Ethicon representatives also intentionally
`
`misrepresented the present financial budgeting and intent of Ethicon to pay for the Work (and extra
`
`work) delivered by Optum pursuant to the change directives of Ethicon, much less Optum 's
`
`invoice subsequently submitted in conformity therewith. Optum shows it justifiably relied upon
`
`Ethicon's misrepresentations to its detriment.
`
`51.
`
`Optum has incurred compensatory damages as a direct and proximate result of Ethicon's
`
`tortious conduct, and the apparent conspiracy of its representatives associated therewith,
`
`in an
`
`amount that shall be established by the evidence adduced at trial.
`
`52.
`
`Optum shows that
`
`the conspiracy and fraudulent conduct engaged in by Ethicon was
`
`entered into and perpetuated with the specific intent of damaging Optum. As such, Optum is
`
`entitled to recover punitive damages over and against Ethicon in an amount to be determined by
`
`14
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 17 of 44
`
`the enlightened conscience of the impartial
`
`trier of fact,
`
`to deter Ethicon from future similar
`
`conduct.
`
`COUNT SEVEN -NEGLIGENT MISREPRESENTATION
`
`53.
`
`Optum incorporates paragraphs 1-52 hereof by reference as if all such paragraph were
`
`.
`
`restated herein verbatim.
`
`54.
`
`Alternatively, Ethicon negligently misrepresented its present financial budgeting and intent
`
`to issue a modified Purchase Order for the AHU 1 7A Project and to pay for the work delivered by
`
`Optum at the direction of Ethicon personnel. Optum justifiably and detrimentally relied upon such
`
`representations by proceeding to perform the Work, and has incurred compensatory damages in
`
`an amount to be established by the evidence at Trial, as a direct and proximate result of such
`
`negligent misrepresentations.
`
`55.
`
`Moreover, the negligent misrepresentations were made in a willful and wanton manner,
`
`with reckless disregard for the consequences of such misrepresentations. As such, Optum is
`
`entitled to an award of punitive damages against Ethicon,
`
`in an amount determined by the
`
`enlightened conscience of the impartial
`
`trier of the fact,
`
`to deter Ethicon from future similar
`
`conduct.
`
`COUNT EIGHT - ENFORCEMENT OF MECHANIC'S LIEN
`
`56.
`
`Optum incorporates paragraphs 1-55 hereof by reference as if all such paragraph were
`
`restated herein verbatim.
`
`15
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 18 of 44
`
`Optum brings this action to enforce its Claim of Lien previously filed against the ownership
`
`57.
`
`interest of Ethicon in the Project.
`
`58.
`
`Accordingly, pursuant to O.C.G.A. § 44-14-361 et seq. and 44-14-364, Optum now brings
`
`this lien enforcement action within 365 days after the filing of its Claim of Lien to liquidate its
`
`claims against Ethicon, and thereby establish a special statutory lien in favor of Optum.
`
`WHEREFORE, Optum prays that process issue, and that Optum be granted the following
`
`relief:
`
`(I)
`
`Judgment
`
`in favor of Optum against Ethicon for
`
`the principal amount of
`
`$951,634.00 plus interest accrued thereon at 18% per annum from the date of each invoice to the
`
`date of judgment, Optum's Overhead and Profit related thereto, as well as the amount of
`
`$82,903.00 remaining owed to Optum on the "Sparks Project", pursuant to Count One;
`
`(2)
`
`Judgment
`
`in favor of Optum against Ethicon in the amount of $951,634.00,
`
`Optum's Overhead and Profit related thereto, as well as the amount of $82,903.00 remaining owed
`
`to Optum on the "Sparks Project", pursuant to Count Two;
`
`(3)
`
`Judgment in favor of Optum against Ethicon, in the amount to be established by the
`
`evidence at trial, pursuant to Count Three;
`
`(4)
`
`J udgment TrTfavbr of "Optum arid agai nst-Etlricon~fo'r_th"e_princ ipaham ount-of
`
`$951,634.00 plus interest at 12% per annum from the date of service of this Complaint upon
`
`Ethicon, Optum's Overhead and Profit related thereto, plus the amount of $82,903.00 remaining
`
`owed to Optum on the "Sparks Project", pursuant to Count Four;
`
`16
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 19 of 44
`
`(5)
`
`Judgment
`
`in favor of Optum against Ethicon,
`
`for Optum's cost of litigation,
`
`including reasonable attorney's fees, incurred by Optum, pursuant to Count Five;
`
`(6)
`
`Judgment
`
`in favor of Optum against Ethicon for compensatory damages in an
`
`amount to be proven by the evidence at trial, but not less than $95 1 ,634.00, together with punitive
`
`damages, pursuant to Count Six;
`
`(7)
`
`Judgment
`
`in favor of Optum against Ethicon for compensatory damages in an
`
`amount to be proven by the evidence at trial, but not less than $95 1 ,634.00, together with punitive
`
`damages, pursuant to Count Seven;
`
`(8)
`
`Judgment awarding Optum a special
`
`lien against the Project
`
`in the amount of
`
`$951,634.00 based upon its claims against Ethicon herein, pursuant to Count Eight; and
`
`(10)
`
`That Optum have such other relief as this Court deems just and proper.
`
`Respectfully submitted this 1 1th day of June, 2021.
`
`FOX ROTHSCHILD LLP
`999 Peachtree Street, Suite 1500
`Atlanta, Georgia 30309
`404-962-1000
`mkeni@foxrothschild.com
`n corser@ fbxroth sch i 1 d . c o m
`
`A/ G. Marshall Kent, Jr
`G. Marshall Kent, Jr.
`Georgia Bar No. 4 1 5 1 29
`Nicholas B. Corser
`Georgia Bar No. 290744
`
`17
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 20 of 44
`Case 1:21-cv-02807-CAP Document 1—1 Filed 07/14/21 Page 20 of 44
`
`EXHIBIT 1
`EXHIBIT 1
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 21 of 44
`
`Ethicon, Inc.
`
`Purchase Order
`
`Supplier :
`OPTUM CONSTRUCTION GROUP LLC - 430060070
`1974 DELTA DRIVE
`GAINESVILLE, GA 30501
`United Slates
`Phone: 1(177)02873093
`Tax: 1(770)2873101
`Contact :
`
`Ship To :
`Ethicon Cornelia Receiving Dock
`655 Ethicon Circle
`Cornelia, GA 30531-0000
`United States
`Phone: 1706-778-2281
`
`Deliver To:
`RAYMOND S HARRIS
`
`Purchase Order Number: 993931848
`Purchase Order Date: Thu, 05 Jul, 201 8
`
`On Behalf Of:
`Requester: RAYMOND HARRIS
`Requester Phone: 1-706-776-5789
`Requisition: PR968271 7
`
`Bill To :
`Ethicon, lnc
`PO Box 16571
`New Brunswick, NJ 08906-657 1
`
`United States
`
`Phone: 1877-557-4487
`
`Other information:
`
`Order Type: Service
`
`Item Part
`Number
`
`Unit Quantity Description
`
`Need Unit Price
`
`Extended
`
`By
`
`Amount
`
`Taxable Service Service
`Close
`
`Open
`
`lot
`
`1
`
`201 8 Optum Construction AHU none SI ,476,274.00 $1,476,274.00 No
`USD
`USD
`1 7 Cornelia
`
`Date
`
`Date
`
`Mon,
`
`Mon,
`
`25 Jun,
`
`31 Dec,
`
`2018
`
`2018
`
`Total
`
`$1,476,274.00
`USD
`
`Comments
`
`• Comments by Ariba System
`information for the purpose of complying with our legal obligations, which include preventing business
`Wc may use your personal
`laws. To learn more about our privacy
`transactions with restricted parlies and complying with relevant global trade control
`—(cid:9)
`(cid:9)
`(cid:9)
`—
`practices see our privacy policy ai www.ap.jnj.conT
`• Comments by Ariba System
`Acceptance and fulfillment of this Service/Purchase Order constitutes your acceptance of the Johnson & Johnson Services, Inc.,
`Service/Purchase Order Terms and Conditions posted on the following Internet site:
`http://www.ap.jnj.eom/gppidocs/webtc_v_l.9.hlm and incorporated herein by reference. If you arc unable to access the site or if
`you have any questions, please contact the Rcquisitioner on this Purchase Order.
`
`This clause applies to all products and/or materials shipped to Johnson & Johnson Affiliates or authorized locations on wooden
`pallets.
`
`Wood Pallets
`
`Wood pallets will be made from wood that is certified to be free of 2, 4, 6-lribromophcnol (TBP) and any other form of phenol-
`based fungicide treatment,and shall comply with the International Standards for Pliyiosanitary Measures Publication No. 15, 2009
`Revision (ISI'M 1 5) for Heal Treatment only. While ISPM 1 5 currently provides for the use of Methyl Bromide (MB), the use of
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 22 of 44
`
`pallets fumigated with Methyl Bromide is also prohibiled.AII wood pallets must properly display that they meet the requirements
`with a specified mark as shown in ISPM 1 5 Annex 11. This requirement is effective immediately, failure to meet this requirement
`may lead to rejection of shipments at supplier's expense.
`• Comments by Ariba System
`FOR YOUR INVOICE TO PAY: All invoices must be sent to the Bill To address on the Purchase Order. Must appear on invoice:
`I) Supplier's Corporate name (must match what is on Purchase order), 2) Purchase Order number (one PO# per invoice), 3) Billing
`and remitting addresses, invoice # and date, 4) Complete description of item or service (should match description on PO), 5) NO
`OVER SHIPMENTS - over shipments will result crediting and re-invoicing a new PO//, 6) Supplier shall ensure that all employees
`who perform duties for Elhicon are aware of and comply with the Johnson & Johnson Policy on Business Conduct and the Johnson
`& Johnson policy on Affirmative Action/Equal Opportunity and Harassment in the Workplace, in connection with the services
`provided to Ethicort as if they were an employee of Elhicon, even though they are not employed by Johnson & Johnson nr F.thicnn.
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 23 of 44
`Case 1:21-cv-02807-CAP Document 1—1 Filed 07/14/21 Page 23 of 44
`
`EXHIBIT 2
`EXHIBIT 2
`
`
`
`Case 1:21-cv-02807-CAP Document 1-1 Filed 07/14/21 Page 24 of 44
`
`(ZfPTUM
`
`V Cw»iiK<'S" Gteup
`
`Estimate Detail
`Ethicon AHU #17
`Cornelia. Ga.
`Presented by Opium Conslruciion Group
`February 9 2018
`
`TcUli QtbKjdig A tea
`
`S.O00
`
`1
`
`<74,45 p-Crtf
`
`t
`
`2.172.23B
`
`OTV
`
`UNTS
`
`Ufiil P(ti;e»
`
`•Price EalonsiDiis-
`
`JJba-r
`
`Mill
`
`Sub
`
`Olhcr
`
`Labor
`
`Mlrl
`
`Sub
`
`Oilier
`
`Total
`
`S/Araa
`
`Description
`GENERAL CONDITIONS
`
`Prpjeci Manager
`Superiniendenl
`
`Temporary Tpilel
`
`irtt
`
`mlhs
`
`i_.A
`1.500,00
`
`n_:o
`
`3.C-3
`
`MO
`a o d
`
`occ
`
`OOP
`
`0.1' 3
`
`0.00
`
`~o.ee
`aoo
`tag oo
`
`*50.00
`
`tfl 400
`W.OOP
`0
`0
`
`0
`
`o
`
`0
`
`0
`
`0
`
`0
`
`0
`
`0
`
`0
`
`0
`
`600
`
`7M0
`
`1 4,400
`
`77.000
`
`ooo
`7200
`
`S.40
`
`o.ll
`
`i .**
`
`66.325 DO
`
`Omtraiier ftno foe
`Tc.-HptH.tiyrqHCO & Qaufc.nlfls
`Ftftl Alt! Kit
`Equipnieiil Rental/ Tools
`fcfac
`Piojcci Cleaning / Ma